Wastebuilt Environmental Solutions, LLC Purchase Order Terms & Conditions
1. Applicability. This purchase order is an offer by Wastebuilt Environmental Solutions, LLC (“Wastebuilt“) for the purchase of the goods, materials and/or equipment (the “Goods“), and/or services, maintenance and/or repairs (the “Services”) specified on the face of this purchase order from the party to whom the purchase order is addressed (the “Seller“) in accordance with and subject to these terms and conditions (the “Terms”); together with the terms and conditions on the face of the purchase order, (the “Order“). Where applicable the term “Goods” shall be interpreted to also include “Services”. This Order, together with any documents incorporated herein by reference, and any related confidentiality agreement executed by the parties, constitute the sole and entire agreement of the parties with respect to the Order, and supersedes all prior or contemporaneous understandings, agreements, negotiations, representations and warranties, and communications, both written and oral, with respect to the subject matter of the Order. The Order expressly limits Seller’s acceptance to the terms of the Order. These Terms prevail over any terms or conditions contained in any other documentation and expressly exclude any of Seller’s general terms and conditions of sale or any other document issued by Seller in connection with this Order. Notwithstanding anything contained herein to the contrary, if a master agreement covering procurement described in the Order exists between Seller and Wastebuilt, the terms of such master agreement shall prevail over any inconsistent terms herein. These Terms apply to any repaired or replacement Goods provided by Seller hereunder. Wastebuilt is not obligated to any minimum purchase or future purchase obligations under this Order, unless agreed to in writing by Wastebuilt.
2. Acceptance. This Order is not binding on Wastebuilt until Seller accepts the Order in writing or starts to perform in accordance with the Order. Wastebuilt may withdraw the Order at any time without liability: (a) before it is accepted by Seller; or, (b) if issued by a non-authorized representative of Wastebuilt (through proper Notice to Seller).
3. Delivery Date. Seller shall deliver the Goods in the quantities and on the date(s) specified in this Order or as otherwise agreed in writing by the parties (the “Delivery Date“). Timely delivery of the Goods is of the essence. If Seller fails to deliver the Goods in full on the Delivery Date, Wastebuilt may terminate the Order immediately by providing written notice to Seller and Seller shall indemnify Wastebuilt against any losses, claims, damages, and reasonable costs and expenses directly attributable to Seller’s failure to deliver the Goods on the Delivery Date. Seller will immediately notify Wastebuilt if Seller’s timely performance under the Order is delayed or is likely to be delayed. Wastebuilt’s acceptance of Seller’s notice will not constitute a waiver of any of Seller’s obligations. Wastebuilt has the right to return any Goods delivered prior to the Delivery Date at Seller’s expense and Seller shall redeliver such Goods on the Delivery Date.
4. Quantity. If Seller delivers more or less than the quantity of Goods ordered, Wastebuilt may reject all or any excess Goods. With regard to the delivery of Wastebuilt owned steel coils being managed by a service center, Wastebuilt may reject any goods in excess of 2% of the ordered quantity of Goods. Any such rejected Goods shall be returned to Seller at Seller’s risk and expense. If Wastebuilt does not reject the Goods and instead accepts the delivery of Goods at the increased or reduced quantity, the Price for the Goods shall be adjusted on a pro-rata basis.
5. Delivery Location. All Goods shall be delivered to the address(s) specified in this Order (the “Delivery Location“) during Wastebuilt’s or Wastebuilt’s customer’s normal business hours or as otherwise instructed by Wastebuilt.
6. Shipping Terms. Delivery of Goods shall be made FOB Delivery Point or as otherwise stated in the Order and in accordance with the terms on the face of this Order. Seller shall give written notice of shipment to Wastebuilt when the Goods are delivered to a carrier for transportation. Seller shall provide Wastebuilt all shipping documents, including the commercial invoice, packing list, air waybill/bill of lading, proof of delivery, and any other documents necessary to release the Goods to Wastebuilt within seven (7) business days after Seller delivers the Goods to the transportation carrier. The Order number must appear on all shipping documents, shipping labels, bills of lading, air waybills, invoices, proofs of delivery, correspondence and any other documents pertaining to the Order.
7. Title and Risk of Loss. Title passes to Wastebuilt upon delivery of the Goods to the Delivery Location. Seller bears all risk of loss or damage to the Goods until delivery of the Goods to the Delivery Location.
8. Packaging. All Goods shall be packed for shipment according to Wastebuilt’s instructions or, if there are no instructions, in a manner sufficient to ensure that the Goods are delivered in undamaged condition. Seller must provide Wastebuilt prior written notice if it requires Wastebuilt to return any packaging material. Any return of such packaging material shall be made at Seller’s expense.
9. Amendment and Modification. No change to this Order is binding upon Wastebuilt unless it is in writing, specifically states that it amends this Order and is signed by an authorized representative of Wastebuilt.
10. Inspection and Rejection. Wastebuilt has the right to inspect the Goods on or after the Delivery Date. Wastebuilt, in its sole discretion and at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective or fail in any respect to conform to specifications, the terms and conditions of the Order, any Statement of Work (“SOW”) or similar document as mutually agreed between the parties, or applicable industry standards, or if the Goods are otherwise deficient in Wastebuilt’s sole discretion. If Wastebuilt rejects any portion of the Goods, Wastebuilt has the right, effective upon written notice to Seller and in addition to any rights and remedies under applicable law, to: (i) rescind the Order in its entirety and receive a full credit or refund, at Wastebuilt’s discretion, of the applicable purchase price; (ii) accept the Goods at a reasonably reduced price; (iii) reject the Goods and require replacement/correction of the rejected Goods; or (iv) replace such defective/non-conforming Goods with similar items and recover the total cost thereof from the Seller. If Wastebuilt requires replacement or correction of the Goods, Seller shall, at its expense, promptly replace/correct the defective or nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of such Goods and the expedited delivery of replacement/corrected Goods. If Seller fails to timely deliver replacement/corrected Goods, Wastebuilt may replace or correct them with goods or services from a third party, and charge Seller the total cost thereof, and terminate this Order for cause pursuant to Section 18. Wastebuilt’s expenses for inspection of the Goods found to be nonconforming or deficient shall be charged to Seller or deducted from amounts due Seller.
Wastebuilt’s failure to detect nonconformities or deficiencies in the Goods shall not affect Wastebuilt’s remedies as to such nonconformities and/or deficiencies.
Any inspection or other action by Wastebuilt under this Section shall not reduce or otherwise affect Seller’s obligations under the Order, and Wastebuilt shall have the right to conduct further inspections after Seller has carried out its remedial actions.
Wastebuilt will have the right, but not the obligation to examine Seller’s records for the purpose of determining compliance with this Order. Should a compliance review be performed, Wastebuilt or its duly designated representatives will provide reasonable notice to Seller and the records may be examined only during the normal business hours. Wastebuilt will bear all audit costs.
11. Price. The price of the Goods and/or Services is the price stated in the Order (the “Price“). If no Price is included in the Order, the Price shall be the price set out in the Exclusive Master Manufacturing and Supply Agreement, SOW or similar document as mutually agreed between the parties. Unless otherwise specified in the Order, the Price includes all packaging, transportation costs to the Delivery Location, insurance, customs duties and fees and applicable taxes, including, but not limited to, all sales, use or excise taxes. No increase in the Price is effective, whether due to increased material, labor or transportation costs or otherwise, without ninety (90) days’ prior written notice to Wastebuilt and the written consent of Wastebuilt. Seller may not change its prices more than one (1) time per year, unless otherwise agreed to in writing between the parties.
12. Most Favored Customer. Seller represents and warrants that the Price for the Goods is the lowest price charged by Seller to any of its external buyers for similar volumes of similar Goods. If Seller charges any other buyer a lower price, Seller must apply that price to all Goods under this Order. If Seller fails to meet the lower price, Wastebuilt, at its option, may terminate this Order and/or any agreement or master agreement associated with this Order associated with this Order without liability pursuant to Section 18.
13. Payment Terms; Set-off. Seller shall issue an invoice to Wastebuilt on or any time after the completion of delivery and only in accordance with the Terms. Wastebuilt shall pay all properly invoiced amounts due to Seller within sixty (60) days after Wastebuilt’s receipt of such invoice, except for any amounts disputed by Wastebuilt in good faith. All payments hereunder will be in US dollars and made by check, ACH, EFT or wire transfer. The parties shall seek to resolve any invoice disputes expeditiously and in good faith. Seller shall continue performing its obligations under the Order notwithstanding any such dispute. Without prejudice to any other right or remedy it may have, Wastebuilt reserves the right to set off at any time any amount owing to it by Seller against any amount payable by Wastebuilt to Seller.
14. Warranties. Seller warrants to Wastebuilt that for a period of the longer of: (1) one (1) year after acceptance of the Goods and Services by Wastebuilt or Wastebuilt’s end user; (2) such longer period of time as the item is normally warranted by Seller; or (3) as agreed to between the parties in writing: (a) all Goods will be free from any defects in workmanship, material and design; (b) all Goods will conform to applicable specifications, drawings, designs, samples and other requirements specified by Wastebuilt, federal, state, and local laws, orders and regulations, including, but not limited to, those regarding occupational safety and health; (c) all Goods will be fit for their intended purpose and operate as intended; (d) all Goods will be merchantable; (e) all Goods will be free and clear of all liens, security interests or other encumbrances; and (f) the Goods will not infringe or misappropriate any third party’s patent or other intellectual property rights. These warranties survive any delivery, inspection, acceptance or payment of or for the Goods by Wastebuilt. These warranties are cumulative and in addition to any other warranty provided by law or equity. Any applicable statute of limitations runs from the date of Wastebuilt’s discovery of the noncompliance of the Goods with the foregoing warranties. If Wastebuilt gives Seller notice of noncompliance with this Section, Seller shall, at its own cost and expense, promptly replace or repair the defective or nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective or nonconforming goods to Seller and the delivery of repaired or replacement Goods to Wastebuilt.
15. General Indemnification. Seller will defend, indemnify and hold harmless Wastebuilt and its parent, and their respective directors, officers, employees, agents, and their respective customers and end users (“Wastebuilt Indemnified Parties”), buying or using the Goods and/or receiving the Services from and against any and all claims (whether in contract, tort and/or any other legal theory including strict liability), demands, suits, obligations, liabilities, damages, losses, and judgments, including reasonable costs and expenses (including, but not limited to, reasonable attorneys’ fees, court costs, and out-of-pocket expenses)(collectively “Losses”) arising directly or indirectly from: (a) any death of or injury to any person, damage to any property or any other damage or loss due to any defect in or use of any Goods provided by Seller under this Agreement, (b) violations or alleged violations of any applicable laws or regulations by Seller; (c) the negligent or wrongful acts or omissions of Seller, its employees or agents; (d) any infringement or misappropriation of patent, copyright, trade secret or other intellectual property rights of any third party or Wastebuilt, or, (e) any products recall. Seller shall not enter into any settlement without Wastebuilt’s or indemnitee’s prior written consent. Wastebuilt shall indemnify and hold Seller harmless from and against any third party claims for Losses arising out of or in connection with Wastebuilt’s grossly negligent or more culpable acts or omission in performance of its obligations herein.
16. Insurance. During the term of the Order and during the term of any applicable warranty period thereafter, Seller shall, at its own expense, maintain and carry insurance in full force and effect which includes, but is not limited to, coverage for liabilities to third parties for bodily injury (personal injury) and damage to property in amounts sufficient to protect Wastebuilt in the event of such injury or damage, and will be in compliance with any and all laws, regulations or orders addressing the liabilities of an employer to its employees for injuries and disease suffered in connection with employment. Seller further will maintain such additional types and limits of insurance as is customary for a company of similar size and similar operations to Seller in the jurisdiction or jurisdictions in which Seller’s operations take place. Upon Wastebuilt’s request, Seller shall provide Wastebuilt with a certificate of insurance from Seller’s insurer evidencing the insurance coverage specified in this Order. The certificate of insurance shall name Wastebuilt and the Wastebuilt Indemnified Parties as additional insureds by endorsement. Seller shall provide Wastebuilt with thirty (30) days’ advance written notice in the event of a cancellation or material change in Seller’s insurance policy. Except where prohibited by law, Seller shall require its insurer to waive all rights of subrogation against Wastebuilt, Wastebuilt’s insurers and the Wastebuilt Indemnified Parties.
17. Compliance with Law. Seller is in compliance with and shall comply with all applicable laws, regulations and ordinances. Seller has and shall maintain in effect all the licenses, permissions, authorizations, consents and permits that it needs to carry out its obligations under the Order, including, but not limited to, the California Transparency in Supply Chains Act and California’s Proposition 65. Seller shall comply with all export and import laws of all countries involved in the sale of Goods under this Order. Seller assumes all responsibility for shipments of Goods requiring any government import clearance. Wastebuilt may terminate this Order if any government authority imposes antidumping duties, countervailing duties or any retaliatory duties on the Goods. Seller shall not discriminate against any employee, applicant for employment, or subcontractor because of race, religion, color, sex, age or national origin. Seller warrants and represents to Wastebuilt that Seller will not obtain materials or information necessary to produce the Goods from manufacturers/sellers/subcontractors where Seller has knowledge or has reason to believe that said manufacturers/sellers/subcontractors utilize forced, prison or child labor, conflict minerals, or any labor force not in compliance with local, state, federal or national laws.
18. Termination. Wastebuilt may terminate this Order, in whole or in part, at any time with or without cause for undelivered Goods upon written Notice to Seller. In addition to any remedies that may be provided under these Terms, Wastebuilt may terminate this Order with immediate effect upon written notice to the Seller, either before or after the acceptance of the Goods, if Seller has not performed or complied with any of these Terms, in whole or in part. If the Seller becomes insolvent, files a petition for bankruptcy or commences or has commenced against it proceedings relating to bankruptcy, receivership, reorganization or assignment for the benefit of creditors, then the Wastebuilt may immediately terminate this Order upon written notice to Seller. If Wastebuilt terminates the Order for any reason, Seller’s sole and remedy is payment for the Goods received and accepted by Wastebuilt prior to the termination. If this Order applies to a particular Wastebuilt facility and such facility closes or relocates to a new location, Wastebuilt may, in its sole discretion, terminate any Order in whole or in part and not currently in production upon written notice to Seller. If Seller closes its facility(ies) or moves to a new location, Wastebuilt may, in its sole discretion, terminate any Order or associated agreement, in whole or in part, not currently in production upon written notice to Seller.
19. Seller’s Changes. Prior to Seller making any changes (“Changes”) to its Goods, including, but not limited to, its raw materials, designs, tooling, manufacturing location or ownership of Seller, Seller shall provide Wastebuilt with ninety (90) days’ prior written notice of such Changes and Wastebuilt will have the right, in its sole discretion, to terminate any and all Orders without liability. If notice of Changes is not given, Seller agrees to reimburse Wastebuilt for any and all costs and damages that arise out of or are related to the Changes.
20. Limitation of Liability. Nothing in this Order shall exclude or limit (a) Seller’s liability under Sections 14, 15, and 22 hereof, or (b) Seller’s liability for fraud, personal injury or death caused by its negligence or willful misconduct. Each party’s maximum liability to the other party shall not exceed the aggregate amount actually paid or payable under this Order. IN NO EVENT WILL WASTEBUILT BE LIABLE TO SELLER FOR ANY INCIDENTAL, INDIRECT, SPECIAL, CONSEQUENTIAL, OR PUNITIVE DAMAGES OR LOSS OF PROFITS ARISING OUT OF, OR IN CONNECTION WITH THE ORDER, INCLUDING BUT NOT LIMITED TO LOSS OF ANTICIPATED OPPORTUNITY OR PROFITS, WHETHER OR NOT WASTEBUILT WAS ADVISED OF THE POSSIBILITY OF SUCH DAMAGE. NOTHING IN THE ORDER LIMITS SELLER’S LIABILITY FOR BODILY INJURY OF A PERSON, DEATH, OR PHYSICAL DAMAGE TO PROPERTY OR ANY LIABILITY WHICH CANNOT BE EXCLUDED UNDER APPLICABLE LAW.
21. Waiver. No waiver by any party of any of the provisions of the Order shall be effective unless explicitly set forth in writing and signed by the party so waiving. Except as otherwise set forth in the Order, no failure to exercise, or delay in exercising, any rights, remedy, power or privilege arising from the Order shall operate or be construed as a waiver thereof, nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.
22. Confidential Information. All non-public, confidential or proprietary information of Wastebuilt, including, but not limited to, specifications, samples, patterns, designs, plans, drawings, documents, data, business operations, customer lists, pricing, discounts or rebates, disclosed by Wastebuilt to Seller, whether disclosed orally or disclosed or accessed in written, electronic or other form or media, and whether or not marked, designated or otherwise identified as “confidential,” in connection with the Order is confidential, solely for the use of performing the Order and may not be disclosed or copied unless authorized by Wastebuilt in writing. Upon Wastebuilt’s request, Seller shall promptly return all documents and other materials received from Wastebuilt. Wastebuilt shall be entitled to injunctive relief for any violation of this Section. This Section shall not apply to information that is: (a) in the public domain; (b) known to the Seller at the time of disclosure; or (c) rightfully obtained by the Seller on a non-confidential basis from a third party.
23. Force Majeure. Neither party shall be liable to the other for any delay or failure in performing its obligations under the Order to the extent that such delay or failure is caused by an event or circumstance that is beyond the reasonable control of that party, without such party’s fault or negligence, and which by its nature could not have been foreseen by such party or, if it could have been foreseen, was unavoidable (“Force Majeure Event“). Force Majeure Events include, but are not limited to, acts of God or the public enemy, government restrictions, floods, fire, earthquakes, explosion, epidemic, war, invasion, hostilities, terrorist acts, riots, strike, embargoes or industrial disturbances. Seller’s economic hardship or changes in market conditions are not considered Force Majeure Events. Seller shall use all diligent efforts to end the failure or delay of its performance, ensure that the effects of any Force Majeure Event are minimized and resume performance under the Order. Seller shall immediately notify Wastebuilt in writing of any Force Majeure Event along with its mitigation plan with specific milestone due dates and provide Wastebuilt with regular weekly, or more frequent, updates as to the status of its mitigation efforts. If a Force Majeure Event prevents Seller from carrying out its obligations under the Order for a continuous period of more than sixty (60) days, Wastebuilt may terminate this Order immediately by giving written notice to Seller.
24. Assignment. Seller shall not assign, transfer, delegate or subcontract any of its rights or obligations under the Order without the prior written consent of Wastebuilt, which consent will not be unreasonably withheld. Any purported assignment or delegation in violation of this Section shall be null and void. No assignment or delegation shall relieve the Seller of any of its obligations hereunder. Wastebuilt may at any time assign, transfer or subcontract any or all of its rights or obligations under the Order without Seller’s prior written consent. If Wastebuilt consents to the use of a subcontractor, Seller will: (i) guarantee and will remain liable for the performance of all subcontracted obligations; (ii) indemnify Wastebuilt for all damages and costs of any kind, incurred by Wastebuilt or any third party and caused by the acts and omissions of Seller’s subcontractors’, and, (iii) make all payments to its subcontractors. If Seller fails to timely pay a subcontractor for work performed, Wastebuilt will have the right, but not the obligation, to pay the subcontractor and offset any amount due to Seller by any amount paid to the subcontractor. Seller will defend, indemnify and hold Wastebuilt harmless for all damages and costs of any kind, without limitation, incurred by Wastebuilt and caused by Seller’s failure to pay a subcontractor.
25. Relationship of the Parties. The relationship between the parties is that of independent contractors. Nothing contained in the Order shall be construed as creating any agency, partnership, joint venture or other form of joint enterprise, employment or fiduciary relationship between the parties, and neither party shall have authority to contract for or bind the other party in any manner whatsoever. No relationship of exclusivity shall be construed from this Order. This Order is for the sole benefit of the parties hereto and their respective successors and permitted assigns and nothing herein, express or implied, is intended to or shall confer upon any other person or entity any legal or equitable right, benefit or remedy of any nature whatsoever under or by reason of these Terms.
26. Governing Law; Jurisdiction. All matters arising out of or relating to this Order shall be governed by and construed in accordance with the internal laws of the State of Illinois without giving effect to any choice or conflict of law provision or rule that would cause the application of the laws of any jurisdiction other than those of the State of Illinois. Any legal suit, action or proceeding arising out of or relating to this Order shall be instituted in the federal courts of the United States of America or the courts of the State of Illinois in each case located in the County of Will, and each party irrevocably submits to the jurisdiction of such courts in any such suit, action or proceeding.
27. Cumulative Remedies. The rights and remedies under this Order are cumulative and are in addition to and not in substitution for any other rights and remedies available at law or in equity or otherwise.
28. Notices. All notices, request, consents, claims, demands, waivers and other communications hereunder (each, a “Notice“) shall be in writing and addressed to the parties at the addresses set forth on the face of this Order or to such other address that may be designated by the receiving party in writing. All Notices shall be delivered by personal delivery, nationally recognized overnight courier (with all fees pre-paid), facsimile (with confirmation of transmission) or certified or registered mail (in each case, return receipt requested, postage prepaid). Except as otherwise provided in this Order, a Notice is effective only (a) upon receipt of the receiving party, and (b) if the party giving the Notice has complied with the requirements of this Section. The parties agree that for any transactions subject to this Order, facsimile signatures shall be accepted as original signatures, orders may be transmitted electronically and any document created pursuant to this order may be maintained in an electronic document storage and retrieval system, a copy of which shall be considered an original. Neither party shall raise any objection to the authenticity of this Order or any document created hereunder, based on the use of a facsimile signature, electronic order or the use of a copy retrieved from an electronic storage system.
29. Severability. If any term or provision of this Order is invalid, illegal or unenforceable in any jurisdiction, such invalidity, illegality or unenforceability shall not affect any other term or provision of this Agreement or invalidate or render unenforceable such term or provision in any other jurisdiction. Upon a determination by a court of law or other authorized body that any term or provision is invalid, illegal or unenforceable, and in the event that the parties are unable in good faith to agree on a replacement term or provision, a court of competent jurisdiction may modify this Order to effect the original intent of the parties as closely as possible.
30. Survival. Provisions of this Order which by their nature should apply beyond their terms will remain in force after any termination or expiration of this Order including, but not limited to, the following provisions: Set-off, Warranties, General Indemnification, Intellectual Property, Indemnification, Insurance, Compliance with Laws, Confidentiality, Governing Law, Submission to Jurisdiction/Arbitration and Survival.
31. Ownership and License. Unless otherwise specified in a SOW or other written agreement between the parties, each party owns all right, title, and interest in and to any of its preexisting materials. Seller hereby grants Wastebuilt a perpetual, irrevocable, worldwide, transferable, royalty-free, nonexclusive license, with the right to sublicense and authorize the granting of sublicenses, to use and reproduce Seller’s preexisting materials in the Goods to the extent necessary for Wastebuilt’s exercise and exploitation of its rights in the Goods. Unless otherwise specified in an SOW or other agreement between the parties, Seller will obtain and assign to Wastebuilt a nonexclusive, royalty-free, worldwide, perpetual, irrevocable, transferable, sub-licensable license to use all third party intellectual property rights incorporated into, required to use, or delivered with the Work. Seller will deliver copies of the above releases and licenses to Wastebuilt upon Wastebuilt’s request.
32. Wastebuilt’s Property; Special Tools, Dies, Molds and Engineering Designs. Seller acknowledges that all materials, including, without limitation, tools, dies, molds and engineering designs furnished or specifically paid for by Wastebuilt (a) shall be and remain the property of Wastebuilt; (b) shall be subject to removal at any time without additional cost upon demand by Wastebuilt; (c) shall be used only in filling the Order for Wastebuilt; (d) shall be kept separate from other materials and tools; and (e) shall be clearly identified as the property of Wastebuilt. Seller assumes all liability for loss of and/or damage to Wastebuilt’s property, with the exception, in the case of molds, tools and dies, of normal wear and tear. Payment for special tools, dies, molds and engineering designs will not be made until such time as Wastebuilt approves samples of produced Goods. If a payment for a special die or mold is made and not included in the unit costs of the produced Goods, the invoice for the produced Goods must state: “A separate payment of US$ [______] was received by us from Wastebuilt in connection with tools/dies/molds used in the production of this merchandise. See Order [______].” If tools, dies, molds or engineering designs are supplied to Seller free of charge by Wastebuilt, the invoice must state: “Molds/tools/dies/engineering designs were supplied free of charge by Wastebuilt and not included in the unit costs above.”
33. Obsolescence. In the event that a Wastebuilt facility shall permanently close, Wastebuilt agrees to pay Seller for any obsolete Seller owned inventory located as such facility provided that Wastebuilt had issued a valid Order or Order release, as the case may be, for such inventory and Seller submits, and Wastebuilt approves (which approval will not be unreasonably withheld), a detailed inventory of the obsolete items. The price of such inventory shall be the list price on the day said Purchase Order was issued or the date of the inventory, whichever is less. Payment to Seller will be made under the normal payment terms set forth in Section 13 herein.
34. Hazardous Materials Reporting. If any of the Goods ordered herein constitute or contain “hazardous or toxic chemicals” as defined by any applicable Federal, State or local law, rule or regulation, Seller shall provide at the time of delivery all required notices and information, including without limitation all Material Safety Data Sheets in approved form. Seller agrees to maintain such information current and shall provide Wastebuilt with any amended, altered or revised information on a timely basis. When this Order or the specifications referred to herein, requires documentation or certification, this requirement is a material requirement of this Order; Seller’s failure to provide such information prior to or at the time of delivery may result in withholding of payment until such is provided.
(WB Rev. 2021.06.15)
Archived Purchase Order Terms and Conditions: